 |
English
|
正體中文
|
简体中文
|
Post-Print筆數 : 27 |
Items with full text/Total items : 112721/143689 (78%)
Visitors : 49545561
Online Users : 786
|
|
|
Loading...
|
Please use this identifier to cite or link to this item:
https://nccur.lib.nccu.edu.tw/handle/140.119/124440
|
| Title: | 從工程承攬契約的兩個實務案型再思考情事變更原則之適用要件──以【物價漲跌型】及【工期展延型】之相關判決為中心
Reconsideration to the Application of the Principle of Clausula Rebus Sic Stantibus from Two Practical Cases of Engineering Contracts: Focus on the Relevant Judgments of 【Price Fluctuation Type】and 【Duration Extension Type】 |
| Authors: | 吳從周 |
| Contributors: | 法學評論 |
| Keywords: | 情事變更;誠信原則;交易基礎;物價漲跌;工期展延
Clausula Rebus Sic Stantibus;Good Faith;Foundation of Transaction;Price Fluctuation;Duration Extension |
| Date: | 2018-06 |
| Issue Date: | 2019-07-24 16:03:23 (UTC+8) |
| Abstract: | 情事變更原則適用於工程承攬契約實務上的兩種主要爭議類型：即【物價漲跌型】及【工期展延型】之難題，最為重要。就【物價漲跌型】而言，客觀情事重大變更發生之時點並不重要，客觀狀態之變更究竟是在訂約前或訂約後發生，並非所問。如果在訂約前情事即已發生變更，但一直到訂約之後才顯現出來或者迄該時點始為當事人所知者，仍應有情事變更之適用，可參考德國民法第313條第1項規定情事變更之要件作解釋。就【工期展延型】而言，則應參考德國民法第313條第2項，承認雙方當事人共同錯誤（純粹主觀交易基礎欠缺或共同評價錯誤）之「主觀交易基礎喪失」，也有情事變更原則之適用。在方法論上，可以考量引用民法第1條將德國民法第313條第2項規定作為外國立法例，引為法理，加以適用。
The Application of the principle of Clausula rebus sic stantibus (change of circumstances) to the two main types of controversial issues in the construction contracts, namely the problems of [price fluctuation type] and [extension of duration] is most important in the court practice. This article asserts that it is necessary to inherit and refer to the basic theory of foundation of transaction (especially the “loss of foundation of subjective transaction theory”) before and after the addition of Article 313 of the German Civil Code. Regarding the price fluctuation type, it does not matter when a major change in objective circumstances occurs. It is not important whether changes in the objective state occurred before or after the contract was made. If there have been some changes in the situation before the contract is made but the change does not occur until the contract has been made or until when the parties have known it—which would definitely interfere with the contractual plan, then the principle of Clausula rebus sic stantibus (change of circumstances) still should be applied since the parties have not been fully understood the situation. Such “objective change” that shakes “society’s existence” is ought to refers to the principle of Clausula rebus sic stantibus (change of circumstances) as stipulated in Article 313, paragraph 1 of the German Law and give its Priority to respect the parties’ risk allocation through the contractual agreement, so far the contractual agreement of exclusion should have their effect. However, if the agreement precludes the principle of Clausula rebus sic stantibus (change of circumstances) from exceeding the inherent limits of risk allocation or if the occurrence and variation of such risk have not been beyond the scope of “general reasonableness” and are unpredictable, it should be declared as void. In accordance with the original agreement of the payment and treatment of the relationship between the performance of the price which is obviously contrary to the contractual justice, it should return to the principle of Clausula rebus sic stantibus (change of circumstances). Additionally, in terms of the extension of schedule, it should be admitted that “the foregoing affair has been changed but not revealed until after the contract has been made, or as of that moment has become known to the parties.” Other than the application of the principle of Clausula rebus sic stantibus (change of circumstances), reference should be made to Article 313, paragraph 2, of the German Civil Code, to recognize that the parties’ subjective errors in the subjective formation of a meaningful event at the time of signing have common mistakes (so called lack of purely subjective transaction basis or common evaluation of mistakes) should apply of the principle of Clausula rebus sic stantibus. As for the methodology, it may be possible to consider the need for equity balance based on the actual needs of the transaction and the case, and to apply the provisions of Article 313, paragraph 2, of German Civil Code as a foreign legislation by reference to the paragraph 1 “nature of things” of Taiwan civil law. |
| Relation: | 法學評論, 153, 1-80 |
| Data Type: | article |
| DOI 連結: | https://doi.org/ 10.3966/102398202018060153001 |
| DOI: | 10.3966/102398202018060153001 |
| Appears in Collections: | [政大法學評論 TSSCI] 期刊論文
|
Files in This Item:
| File |
Description |
Size | Format | |
|---|
| 64.pdf | | 605Kb | Adobe PDF2 | 205 | View/Open |
|
All items in 政大典藏 are protected by copyright, with all rights reserved.
|
著作權政策宣告 Copyright Announcement1.本網站之數位內容為國立政治大學所收錄之機構典藏，無償提供學術研究與公眾教育等公益性使用，惟仍請適度，合理使用本網站之內容，以尊重著作權人之權益。商業上之利用，則請先取得著作權人之授權。
The digital content of this website is part of National Chengchi University Institutional Repository. It provides free access to academic research and public education for non-commercial use. Please utilize it in a proper and reasonable manner and respect the rights of copyright owners. For commercial use, please obtain authorization from the copyright owner in advance.
2.本網站之製作，已盡力防止侵害著作權人之權益，如仍發現本網站之數位內容有侵害著作權人權益情事者，請權利人通知本網站維護人員(
nccur@nccu.edu.tw)，維護人員將立即採取移除該數位著作等補救措施。
NCCU Institutional Repository is made to protect the interests of copyright owners. If you believe that any material on the website infringes copyright, please contact our staff(
nccur@nccu.edu.tw). We will remove the work from the repository and investigate your claim.
